Conditions governing the use of our website and professional services
These Terms of Service constitute a legally binding agreement between you, whether personally or on behalf of an entity, and ABARCA ROOFING LLC, a company organized under the laws of the United States with its principal place of business located at 396 S 300 E, American Fork, UT 84003-2420, United States, concerning your access to and use of the website located at https://www.abarcaroof.lat as well as any related services, consulting, or roofing work provided by ABARCA ROOFING LLC. By accessing our website, engaging our services, or otherwise interacting with ABARCA ROOFING LLC, you agree to be bound by these Terms of Service. If you do not agree with any portion of these Terms, you must immediately discontinue your use of our website and services.
ABARCA ROOFING LLC
Address: 396 S 300 E, American Fork, UT 84003-2420, United States
Website: https://www.abarcaroof.lat
Email: help@abarcaroof.lat
Phone: +1 (936) 667-2838
IMPORTANT NOTICE — PLEASE READ CAREFULLY: These Terms of Service contain provisions that limit our liability to you and require you to resolve disputes with us through binding arbitration on an individual basis rather than through jury trials or class actions. By agreeing to these Terms, you waive your right to participate in class action lawsuits or class-wide arbitration against ABARCA ROOFING LLC. Please review the Dispute Resolution section below for full details.
Throughout these Terms of Service, the following terms shall have the meanings set forth below. The term Company, We, Us, or Our refers to ABARCA ROOFING LLC, including its owners, officers, employees, agents, contractors, and affiliates. The term You or Your refers to the individual accessing or using our website and services, or the legal entity on whose behalf such individual is acting. The term Website refers to the website located at https://www.abarcaroof.lat and all subdomains, subdirectories, and pages accessible through that domain. The term Services refers to all roofing installation, repair, maintenance, inspection, consulting, computer-integrated systems design, and any other professional or technical services provided by ABARCA ROOFING LLC. The term Content refers to all text, images, graphics, photographs, videos, audio, data, software, and any other materials displayed on or made available through our Website.
In these Terms of Service, unless the context otherwise requires, words in the singular include the plural and vice versa, words importing any gender include all genders, and references to persons include natural persons, corporations, partnerships, limited liability companies, trusts, and other legal entities. The headings used in these Terms are for convenience only and shall not affect the interpretation of the provisions. Any reference to a statute, regulation, or legal provision includes any amendments, re-enactments, or replacements thereof. The word including or includes shall be construed as meaning including without limitation unless expressly stated otherwise.
By accessing or using the Website, by contacting ABARCA ROOFING LLC for any purpose, or by engaging our Services in any manner, you acknowledge that you have read, understood, and agree to be bound by these Terms of Service and by our Privacy Policy, which is incorporated herein by reference. You represent and warrant that you are at least 18 years of age and have the legal capacity to enter into a binding contract. If you are using the Website or engaging our Services on behalf of an organization or entity, you represent and warrant that you have the authority to bind that organization to these Terms and that the organization agrees to be bound by them. We reserve the right to update, amend, or replace these Terms of Service at any time at our sole discretion. Any changes will be effective immediately upon posting the revised Terms on the Website, and your continued use of the Website or Services after any such changes constitutes your acceptance of the updated Terms.
ABARCA ROOFING LLC provides professional roofing services including but not limited to residential and commercial roof installation, roof replacement, roof repair, emergency leak repair, roof inspection and condition assessment, preventive maintenance programs, solar roof integration, gutter system installation and repair, skylight installation, attic ventilation solutions, and consulting services related to roofing systems. In addition to traditional roofing services, ABARCA ROOFING LLC provides computer-integrated systems design services, utilizing advanced software and technology platforms for project planning, aerial surveying, thermal imaging diagnostics, materials optimization, and construction project management. Our services are offered within the Professional, Scientific, and Technical Services sector as defined by industry classification standards.
The descriptions of services provided on our Website are for informational purposes only and do not constitute a binding offer to perform any specific service. Actual services will be defined in a separate written agreement, estimate, or proposal executed between you and ABARCA ROOFING LLC for each specific project. Pricing, timelines, material specifications, and scope of work are subject to site-specific assessment and will be documented in a formal service agreement. ABARCA ROOFING LLC reserves the right to decline to provide services to any person or entity for any reason not prohibited by applicable law.
ABARCA ROOFING LLC primarily provides services within the state of Utah, including American Fork, Lehi, Provo, Orem, Pleasant Grove, Lindon, Highland, Alpine, Cedar Hills, Saratoga Springs, Eagle Mountain, and surrounding communities along the Wasatch Front. Service availability for locations outside this primary service area is subject to determination on a case-by-case basis. Contacting us does not guarantee that we are able or willing to provide services at your location.
Subject to your compliance with these Terms of Service, ABARCA ROOFING LLC grants you a limited, non-exclusive, non-transferable, revocable license to access and view the Content on our Website for your personal, non-commercial use in connection with evaluating and engaging our Services. This license does not grant you any right to reproduce, distribute, modify, create derivative works from, publicly display, publicly perform, transmit, or otherwise exploit any Content on the Website without the prior written consent of ABARCA ROOFING LLC.
All Content on the Website, including without limitation the text, graphics, logos, icons, images, photographs, videos, audio clips, digital downloads, data compilations, software code, page layout, design elements, color schemes, and the overall look and feel of the Website, is the exclusive property of ABARCA ROOFING LLC or its content suppliers and is protected by United States and international copyright, trademark, patent, trade secret, and other intellectual property laws. The ABARCA name, the ABARCA ROOFING logo, and all related marks, names, and slogans are trademarks of ABARCA ROOFING LLC. You may not use any such trademarks without our prior written permission.
In connection with your use of the Website, you agree not to engage in any of the following prohibited activities. You shall not use the Website for any unlawful purpose or in violation of any applicable federal, state, local, or international law or regulation. You shall not attempt to gain unauthorized access to any portion of the Website, the server on which the Website is stored, or any server, computer, or database connected to the Website. You shall not use any automated means such as robots, spiders, crawlers, or scrapers to access, copy, or monitor any portion of the Website or its Content without our prior written authorization. You shall not interfere with or disrupt the proper functioning of the Website or the servers and networks that host it. You shall not introduce any viruses, malware, Trojan horses, ransomware, or other harmful or malicious code to the Website. You shall not use the Website to harass, abuse, defame, or otherwise harm any person or entity. You shall not attempt to reverse engineer, decompile, or disassemble any software used in connection with the Website.
By submitting information to ABARCA ROOFING LLC through our Website contact forms, email communications at help@abarcaroof.lat, telephone calls to +1 (936) 667-2838, or any other communication channel, you represent and warrant that all information you provide is accurate, current, and complete. You agree not to submit any information that is false, misleading, fraudulent, or that you do not have the right to disclose. ABARCA ROOFING LLC relies on the accuracy of the information you provide when preparing estimates, scheduling services, and communicating with you about your project.
If you provide ABARCA ROOFING LLC with any feedback, suggestions, ideas, recommendations, or proposals regarding our Website, Services, or business operations, you acknowledge and agree that such submissions are non-confidential and become the sole property of ABARCA ROOFING LLC. We shall be entitled to use, reproduce, modify, adapt, publish, translate, distribute, and display such feedback for any purpose without compensation or acknowledgment to you. You waive any moral rights or claims of attribution you may have in any feedback you provide.
Any estimate, quotation, or proposal provided by ABARCA ROOFING LLC is valid only for the period stated therein or, if no period is stated, for thirty calendar days from the date of issuance. All estimates are based on the scope of work described in the estimate, prevailing material costs at the time the estimate is prepared, and the conditions observed during any initial assessment. If additional work is required due to conditions not observable during the initial assessment, such as hidden water damage, structural deficiencies, or code compliance issues, ABARCA ROOFING LLC will provide a revised estimate or change order before proceeding with such additional work.
All prices are stated in United States Dollars unless otherwise specified. Prices for materials and services are subject to change without prior notice on the Website. For contracted projects, the price set forth in the signed service agreement shall govern, subject to adjustments through mutually agreed change orders. ABARCA ROOFING LLC is not responsible for price fluctuations in materials that occur after an estimate is issued but before a binding contract is executed.
Payment terms for services rendered by ABARCA ROOFING LLC will be specified in the individual service agreement for each project. Unless otherwise agreed in writing, payment is due according to the schedule set forth in the service agreement. Late payments may be subject to finance charges at the maximum rate permitted by applicable law. ABARCA ROOFING LLC reserves the right to suspend or terminate services if payment is not received in accordance with the agreed terms. You shall be responsible for all costs of collection, including reasonable attorneys fees and court costs, incurred by ABARCA ROOFING LLC in collecting any past-due amounts.
ABARCA ROOFING LLC warrants that all roofing installation and repair work performed by our employees and contractors will be completed in a professional and workmanlike manner consistent with industry standards. The specific terms, duration, and scope of any workmanship warranty will be set forth in the written service agreement for each project. This workmanship warranty is separate from and in addition to any manufacturer warranties that may apply to materials used in the project, which are provided solely by the material manufacturer and are subject to the terms and conditions of those manufacturers.
Roofing materials installed by ABARCA ROOFING LLC may be covered by manufacturer warranties. The terms, coverage, duration, and limitations of manufacturer warranties are determined solely by the respective manufacturers and are not within the control of ABARCA ROOFING LLC. We will assist you in understanding and registering for applicable manufacturer warranties, but ABARCA ROOFING LLC does not assume any obligation or liability under any manufacturer warranty. All warranty claims related to material defects must be pursued directly with the manufacturer according to their claims procedures.
Our workmanship warranty does not cover damage or defects resulting from causes beyond our control, including without limitation: damage caused by severe weather events such as hail, windstorms, tornadoes, hurricanes, lightning, or heavy snow loads; damage caused by falling objects such as tree limbs or debris; damage resulting from fire, flood, earthquake, or other natural disasters or acts of God; damage caused by improper maintenance, neglect, or failure to perform recommended maintenance; damage resulting from foot traffic on the roof by persons not authorized by ABARCA ROOFING LLC; damage caused by modifications, alterations, or repairs performed by parties other than ABARCA ROOFING LLC; damage caused by pests, animals, or biological growth; normal wear and tear, fading, or gradual deterioration over time; and damage to interior finishes or personal property due to leaks that occur after the warranty period.
EXCEPT AS EXPRESSLY SET FORTH IN A WRITTEN SERVICE AGREEMENT, THE WEBSITE AND ALL SERVICES ARE PROVIDED ON AN AS IS AND AS AVAILABLE BASIS WITHOUT ANY REPRESENTATIONS OR WARRANTIES OF ANY KIND, WHETHER EXPRESS OR IMPLIED. TO THE FULLEST EXTENT PERMITTED BY APPLICABLE LAW, ABARCA ROOFING LLC DISCLAIMS ALL IMPLIED WARRANTIES, INCLUDING WITHOUT LIMITATION THE IMPLIED WARRANTIES OF MERCHANTABILITY, FITNESS FOR A PARTICULAR PURPOSE, TITLE, AND NON-INFRINGEMENT. ABARCA ROOFING LLC DOES NOT WARRANT THAT THE WEBSITE WILL BE UNINTERRUPTED, ERROR-FREE, SECURE, OR FREE FROM VIRUSES OR OTHER HARMFUL COMPONENTS, OR THAT ANY DEFECTS OR ERRORS WILL BE CORRECTED. ANY CONTENT DOWNLOADED OR OTHERWISE OBTAINED THROUGH THE USE OF THE WEBSITE IS ACCESSED AT YOUR OWN RISK, AND YOU SHALL BE SOLELY RESPONSIBLE FOR ANY DAMAGE TO YOUR COMPUTER SYSTEM OR LOSS OF DATA THAT RESULTS FROM SUCH DOWNLOADS.
TO THE MAXIMUM EXTENT PERMITTED BY APPLICABLE LAW, IN NO EVENT SHALL ABARCA ROOFING LLC, ITS OWNERS, OFFICERS, DIRECTORS, EMPLOYEES, AGENTS, CONTRACTORS, OR AFFILIATES BE LIABLE FOR ANY INDIRECT, INCIDENTAL, SPECIAL, CONSEQUENTIAL, EXEMPLARY, OR PUNITIVE DAMAGES OF ANY KIND, INCLUDING WITHOUT LIMITATION LOST PROFITS, LOST REVENUE, LOST SAVINGS, LOSS OF DATA, LOSS OF BUSINESS OPPORTUNITY, LOSS OF GOODWILL, BUSINESS INTERRUPTION, OR PERSONAL INJURY OR PROPERTY DAMAGE, ARISING OUT OF OR RELATED TO YOUR USE OF THE WEBSITE, YOUR ENGAGEMENT OF OUR SERVICES, OR THESE TERMS OF SERVICE, WHETHER BASED ON WARRANTY, CONTRACT, TORT INCLUDING NEGLIGENCE, STRICT LIABILITY, OR ANY OTHER LEGAL THEORY, EVEN IF ABARCA ROOFING LLC HAS BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGES. IN ANY EVENT, THE TOTAL AGGREGATE LIABILITY OF ABARCA ROOFING LLC FOR ANY CLAIMS ARISING OUT OF OR RELATED TO THESE TERMS OF SERVICE OR THE SERVICES PROVIDED SHALL NOT EXCEED THE TOTAL AMOUNT PAID BY YOU TO ABARCA ROOFING LLC FOR THE SPECIFIC SERVICE THAT GAVE RISE TO THE CLAIM DURING THE TWELVE MONTHS PRECEDING THE EVENT GIVING RISE TO THE CLAIM, OR ONE THOUSAND DOLLARS IF YOU HAVE NOT MADE ANY PAYMENTS TO ABARCA ROOFING LLC.
You acknowledge and agree that the limitation of liability provisions set forth in this section are fundamental elements of the basis of the bargain between you and ABARCA ROOFING LLC and that ABARCA ROOFING LLC would not be able to provide its Services on an economically feasible basis without such limitations. The limitations of liability set forth herein shall survive and apply even if any limited remedy specified in these Terms is found to have failed of its essential purpose.
You agree to indemnify, defend, and hold harmless ABARCA ROOFING LLC and its owners, officers, directors, employees, agents, contractors, affiliates, successors, and assigns from and against any and all claims, damages, losses, liabilities, costs, and expenses, including reasonable attorneys fees and court costs, arising out of or related to your use of the Website, your violation of these Terms of Service, your violation of any applicable law or regulation, your violation of the rights of any third party, including intellectual property rights or privacy rights, any misrepresentation made by you in connection with your use of the Website or engagement of Services, or any act or omission by you or your agents that causes damage to property or injury to persons at a project site. ABARCA ROOFING LLC reserves the right, at its own expense, to assume the exclusive defense and control of any matter otherwise subject to indemnification by you, in which event you shall cooperate fully with ABARCA ROOFING LLC in asserting any available defenses. You shall not settle any claim that imposes any obligation or liability on ABARCA ROOFING LLC without our prior written consent.
In the event of any dispute, claim, question, or disagreement arising out of or relating to these Terms of Service, the Website, or the Services provided by ABARCA ROOFING LLC, the parties shall first attempt to resolve the dispute informally through good faith negotiations. The party raising the dispute shall provide written notice to the other party describing the nature and basis of the dispute and the relief sought. The parties shall then have a period of thirty calendar days from the date of such notice to attempt to resolve the dispute through direct communication and negotiation.
If the parties are unable to resolve a dispute through informal negotiation within the thirty-day period described above, the dispute shall be resolved exclusively through binding arbitration administered by the American Arbitration Association in accordance with its Commercial Arbitration Rules. The arbitration shall be conducted by a single arbitrator mutually agreed upon by the parties or, if the parties cannot agree, appointed by the American Arbitration Association in accordance with its rules. The arbitration shall be conducted in Utah County, State of Utah, or at another location mutually agreed upon by the parties. The arbitrator shall have the authority to award any remedy or relief that a court of competent jurisdiction could order or grant, including the issuance of injunctive relief and the award of attorneys fees and costs where permitted by applicable law. The arbitrators decision and award shall be final and binding, and judgment on the award may be entered in any court having jurisdiction.
YOU AND ABARCA ROOFING LLC EACH AGREE THAT ANY DISPUTE RESOLUTION PROCEEDINGS WILL BE CONDUCTED ONLY ON AN INDIVIDUAL BASIS AND NOT IN A CLASS, CONSOLIDATED, COLLECTIVE, OR REPRESENTATIVE ACTION. YOU AND ABARCA ROOFING LLC EACH WAIVE ANY RIGHT TO A JURY TRIAL AND ANY RIGHT TO PARTICIPATE AS A PLAINTIFF OR CLASS MEMBER IN ANY PURPORTED CLASS ACTION, CLASS ARBITRATION, PRIVATE ATTORNEY GENERAL ACTION, OR OTHER REPRESENTATIVE PROCEEDING. Unless both you and ABARCA ROOFING LLC agree otherwise in writing, the arbitrator may not consolidate more than one persons claims and may not otherwise preside over any form of a representative or class proceeding. If this class action and jury trial waiver is found to be unenforceable with respect to any particular claim or request for relief, then that claim or request for relief shall be severed from the arbitration and may be brought exclusively in the state or federal courts located in Utah County, State of Utah.
These Terms of Service and any dispute arising out of or related to them shall be governed by and construed in accordance with the laws of the State of Utah, without giving effect to any conflict of laws principles that would result in the application of the laws of another jurisdiction. The United Nations Convention on Contracts for the International Sale of Goods shall not apply to these Terms. For any claims not subject to arbitration as set forth above, you and ABARCA ROOFING LLC agree to submit to the exclusive personal jurisdiction and venue of the state and federal courts located in Utah County, State of Utah.
You may terminate your agreement to these Terms of Service at any time by ceasing all use of the Website and notifying ABARCA ROOFING LLC in writing of your termination. Termination of these Terms does not relieve you of any obligations under any existing service agreement, nor does it affect any rights or obligations that have accrued prior to the effective date of termination. Any provisions of these Terms that by their nature should survive termination, including without limitation the provisions concerning intellectual property, limitation of liability, indemnification, and dispute resolution, shall continue in full force and effect after termination.
ABARCA ROOFING LLC reserves the right to suspend or terminate your access to the Website, or to decline to provide Services to you, at any time, with or without cause, and with or without prior notice. Grounds for termination may include without limitation violation of these Terms of Service, abusive or threatening conduct toward our employees or contractors, failure to make payments when due, provision of false or misleading information, or any conduct that ABARCA ROOFING LLC determines, in its sole discretion, to be detrimental to its business interests or reputation.
These Terms of Service, together with our Privacy Policy and any written service agreement executed between you and ABARCA ROOFING LLC, constitute the entire agreement between you and ABARCA ROOFING LLC with respect to the subject matter hereof and supersede all prior and contemporaneous understandings, agreements, representations, and warranties, whether written or oral, with respect to such subject matter.
If any provision of these Terms of Service is found by a court or arbitrator of competent jurisdiction to be invalid, illegal, or unenforceable for any reason, that provision shall be deemed modified to the minimum extent necessary to make it valid, legal, and enforceable while preserving its intent as closely as possible. If such modification is not possible, the provision shall be severed from these Terms, and the remaining provisions shall continue in full force and effect. The invalidity of any provision shall not affect the validity or enforceability of any other provision of these Terms.
No failure or delay by ABARCA ROOFING LLC in exercising any right, power, or privilege under these Terms of Service shall operate as a waiver thereof, nor shall any single or partial exercise of any right, power, or privilege preclude any other or further exercise thereof or the exercise of any other right, power, or privilege. A waiver of any breach or default under these Terms shall not constitute a waiver of any subsequent breach or default. No waiver shall be effective unless made in writing and signed by an authorized representative of ABARCA ROOFING LLC.
You may not assign, transfer, delegate, or subcontract any of your rights or obligations under these Terms of Service without the prior written consent of ABARCA ROOFING LLC. Any attempted assignment or transfer in violation of this provision shall be null and void. ABARCA ROOFING LLC may assign, transfer, or delegate its rights and obligations under these Terms without restriction and without notice to you. These Terms shall be binding upon and inure to the benefit of the parties hereto and their respective successors and permitted assigns.
ABARCA ROOFING LLC shall not be liable for any failure or delay in the performance of its obligations under these Terms or any service agreement if such failure or delay is caused by circumstances beyond its reasonable control, including without limitation acts of God, fire, flood, earthquake, severe weather, war, terrorism, civil unrest, epidemic or pandemic, government orders or restrictions, labor disputes, supply chain disruptions, material shortages, power outages, or telecommunications failures. The time for performance of any affected obligation shall be extended for a period equal to the duration of the force majeure event plus a reasonable period for recovery.
All notices, requests, demands, and other communications required or permitted under these Terms of Service shall be in writing. Notices to ABARCA ROOFING LLC shall be sent to help@abarcaroof.lat or by certified mail, return receipt requested, to ABARCA ROOFING LLC, 396 S 300 E, American Fork, UT 84003-2420, United States. Notices to you may be sent to the email address or physical address you have provided to us. Notices sent by email shall be deemed received on the date sent if sent before 5:00 PM Mountain Time on a business day, and otherwise on the next business day.
Nothing in these Terms of Service shall be construed to create a partnership, joint venture, agency, employment, or franchise relationship between you and ABARCA ROOFING LLC. Neither party has the authority to bind the other or to incur any obligation on the others behalf without the others prior written consent. ABARCA ROOFING LLC performs services as an independent contractor, and all persons engaged by ABARCA ROOFING LLC in performing services are employees or subcontractors of ABARCA ROOFING LLC and not of the client.
If you have any questions, concerns, or comments about these Terms of Service, or if you need to provide any notice required or permitted hereunder, please contact ABARCA ROOFING LLC using the information below. We strive to respond to all inquiries within two business days.
ABARCA ROOFING LLC
Address: 396 S 300 E, American Fork, UT 84003-2420, United States
Email: help@abarcaroof.lat
Phone: +1 (936) 667-2838
Website: https://www.abarcaroof.lat
Business Hours: Monday through Friday, 8:00 AM to 5:00 PM Mountain Time, excluding federal holidays
These Terms of Service were last updated on July 1, 2026. Previous versions are available upon request by contacting us at help@abarcaroof.lat.